§ 17.30.020. Utility contractor license—Bond.

Latest version.

Insurance or surety as required by State law shall be filed with the Director of Planning and Zoning by each utility contractor before issuance of the utility license, conditioned upon the full completion of all contracted utility work and satisfaction of any judgment or execution issued against the utility contractor because of failure to complete utility work or to pay for labor or materials in the work.

(Ord. O-26-03 § 1 (part): Ord. O-61-94 § 1 (part))

(Ord. No. O-12-16 Amended, § I, 5-23-2016)

                    
                        var val = document.getElementById('citecontent').innerHTML;
                        art.dialog.defaults.title = window.location.href;
                        art.dialog.data('cite', val);
                        art.dialog.data('homeDemoPath', '/Scripts/plus/artDialog/');
                        art.dialog.open('/Scripts/plus/artDialog/citeiframe.html');